Effective March 21, 2017
For a PDF version of this document Click Here
The following are Matson’s current terms and conditions for contracts, purchase orders, work orders, and service purchase orders issued to suppliers of labor, workmanship, materials, equipment, supplies, transportation and supervision for all Matson entities. The terms and conditions are incorporated in each purchase order, work order or service purchase order issued by the companies.
STANDARD TERMS AND CONDITIONS
- DEFINITIONS. As used herein and in this Contract, this Purchase Order, this Work Order or this Service Purchase Order (the “Order”), “Matson” means Matson Navigation Company, Inc. or its parent or any subsidiary or affiliated company if it is acting for such company in connection with the Order. “Contractor” means the person, firm or corporation or other entity accepting this Order for the merchandise or work described on the face hereof. The term “merchandise” and the term “work” include all labor, workmanship, materials, equipment, supplies, transportation and supervision necessary to the proper and complete fulfillment of the requirements of this Order.
- GENERAL STATEMENT REGARDING MERCHANDISE AND WORK. Contractor shall supply all merchandise and furnish all work called for by this Order in strict accordance with the terms hereof for the consideration herein stated. Contractor expressly warrants that work covered by this Order shall be performed in a workmanlike manner and in accordance with good commercial practice, and merchandise supplied against this Order shall: be of merchantable quality, strictly conform to stated specifications, properly serve the purpose intended for the normal useful life of said merchandise, be new, suitable and of the best quality for the purpose intended and conform to and have the benefit of any warranties or guarantees contained in this Order or in Contractor’s proposal. In cases in which a master agreement exists, all merchandise supplied or work performed by Contractor under this Order shall be in accordance with the terms and conditions of the master agreement between Matson and Contractor, which terms and conditions are incorporated herein by reference. In case of conflict, the terms of such master agreement shall prevail.
- INSPECTION. All merchandise supplied and work performed hereunder shall be subject to inspection and tests at any time or place by Matson or any person or agency designated by Matson, even though payment therefor has already been made. Final inspection shall be made upon delivery and acceptance of the merchandise or completion of the work. If upon inspection the merchandise or work is defective or is unsatisfactory because it fails to conform to the plans and specifications or express or implied warranties, Matson shall, in addition to all other legal remedies, be entitled to reject such portion of the merchandise or work and, at its option, either require Contractor to cure such defect or failure to conform or refund to Matson any part of the contract price previously paid for such defective or unsatisfactory work and reimburse Matson for any charges which may have been incurred by Matson in connection therewith, including, without limitation, transportation, handling, insurance, installation, removal and storage. Failure to inspect or failure to discover any defects shall in no way limit Matson’s right to recover against Contractor and to assert any legal remedies Matson may have.
- INVOICES. Payment will be made only on invoices stating the Order number appearing on the face of this Order. All items assigned the same Order number must be billed on a common invoice. Each invoice shall include (i) a complete description of the merchandise delivered or work accomplished under each separate item authorized on the face of this Order; (ii) the dates of delivery of the merchandise or commencement and completion of the work; (iii) the overtime differential, if any, applicable to each item for which overtime work was authorized by Matson; and (iv) discount terms of payment, if any. Cash discount periods shall begin from a date not earlier than the date Matson receives a correct and complete invoice and, for merchandise, the bill of lading or other document evidencing shipment or receipt covering any part of the merchandise.
- DELAYS OR SHORTAGES, FAILURE TO PERFORM. Time is of the essence in the performance of this Order. Contractor shall advise Matson immediately of any shortage or delay in shipment of merchandise or in performance of work in accordance with the terms and conditions of this Order. Matson reserves the right to cancel all or any part of this Order for any material delay. Materiality shall be determined with respect to the merchandise or work to be supplied under this Order and not with respect to the business or assets of Matson. Matson may, at its option, accept delayed delivery or performance from the Contractor without thereby waiving its right to demand strict compliance with the delivery or performance schedule as set forth in this Order with respect to all other deliveries or performances and without prejudice to Matson’s right to recover damages for any delays.
- EXTENSION OF TIME FOR COMPLETION. The date for delivery of the merchandise or completion of work stated on the face of this Order shall be extended in the event of any delay caused by Matson, or in the event of delay beyond the control of Contractor due to government priorities, intervention or delays caused by civil, naval, or military authorities, acts of God (other than ordinary storms), earthquakes, explosions, lightning, flood, fire, strikes or other industrial disturbances, riots, insurrections, war, sabotage, vandalism, blockades, embargoes and epidemics, and only if and to the extent caused by one or more of the foregoing causes. Upon the occurrence of any such delaying event, when knowledge thereof has come to Contractor, written notice shall be given promptly by Contractor to Matson. With the cessation of any such event, written notice thereof and of the anticipated effect thereof shall be given promptly by Contractor to Matson. Matson shall notify Contractor promptly of Matson’s agreement or disagreement with Contractor’s claim for extension of the date for completion of work or delivery of the merchandise.
- LIABILITY AND INSURANCE
- Contractor shall defend, indemnify and hold harmless Matson, its affiliated companies and their officers, directors, agents and employees, from and against all claims, suits (including counsel fees and other costs and expenses of claims or suits, whether groundless or not), liabilities, judgments, and awards on account of and damage to property or any injury or death to persons, together with incidental and consequential damages, which may be caused or be alleged to have been caused in whole or in part by the negligence or other fault of Contractor or any subcontractor or by any failure of merchandise or work performed to conform to warranty.
- Contractor shall continuously insure its general public liability risks (including products and completed operations) with limits of not less than $1,000,000 per accident or occurrence for bodily injury and property damage, unless other amounts are stated in this Order, together with standard workers compensation and employers liability insurance, including Longshore Act and maritime coverage endorsements, as may be applicable, in accordance with federal and state laws. Contractor shall require that any subcontractors meet the insurance requirements set forth in this paragraph. At Matson’s request, Contractor shall provide Matson with evidence of such insurance satisfactory to Matson.
- Indemnity. Contractor shall defend and indemnify Matson from and against any claims and demands for infringement of any patents, trademarks, copyrights or trade secrets covering the whole or any portion of the merchandise or work unless the acts giving rise to the asserted infringement were required or specified by Matson. Contractor shall be responsible for all costs, expenses, including attorneys’ fees and damages incurred or expended in connection with such claims and demands and for procuring the right for Matson to continue to use the product embodying the work. Matson shall defend and indemnify Contractor from and against any claims and demands for infringement of any patents, trademarks, copyrights or trade secrets covering the whole or any portion of the merchandise or work if the acts giving rise to the asserted infringement were required or specified by Matson.
- License. Unless otherwise expressly agreed in writing, Contractor grants Matson a perpetual, irrevocable, worldwide, non-exclusive and royalty free license to use, modify and sell or assign any work or merchandise embodying any patents, trademarks, copyrights or trade secrets created or developed by Contractor, or any subcontractor, in the performance of the work or as part of the merchandise. Contractor shall promptly disclose to Matson each such patent, trademark, copyright or trade secret and each invention, design, discovery or improvement eligible for patent, trademark, copyright or trade secret protection. If any part of the work is to be performed by a subcontractor, Contractor shall cause to be included in the subcontract a like provision by which the subcontractor undertakes the same obligations as Contractor undertakes by reason of the provisions in this subparagraph.
- Confidential Information. Contractor shall maintain in strict confidence both during and after the term of this Order, and shall not disclose to third parties except with the prior written approval of Matson, all confidential business and trade information which it receives from Matson or which is invented, made or developed pursuant to this Order. At Matson’s request, Contractor, Contractor’s employees and subcontractors shall execute confidentiality agreements.
The following additional requirements shall apply with respect to any work done on facilities, vessels or other premises owned, chartered, leased or otherwise used by Matson:
- Insurance. Contractor shall maintain at its sole expense (and shall cause each of its subcontractors performing any services hereunder to maintain) the following insurance policies with insurance companies having a B+ or better A.M. Best rating:
- Commercial General Liability insurance, including contractual liability coverage, with a minimum limit of $1,000,000 per occurrence for bodily injury, personal injury and property damage.
- Commercial Automobile Liability insurance with a minimum combined single limit for bodily injury and property damage of $1,000,000 per occurrence covering all vehicles owned or used by Contractor in performing work.
- Statutory Workers’ Compensation as required by (and which insurance shall be in conformity with) applicable law to further include voluntary compensation coverage, other states coverage for all employees. If the work is performed on or adjacent to navigable waterways, then the policy must include U.S. Longshore and Harbor Workers’ Compensation coverage and Maritime coverage.
- Employers’ Liability insurance with limits of $1,000,000 for each employee, $1,000,000 policy limit by disease, and $1,000,000 for each accident.
- Other insurance policies or increased insurance limits may be prescribed by Matson from time to time based on the materials ordered or work to be performed.
- Security Training. Contractor must provide annual certifications to Matson that Contractor’s employees have attended security awareness training as required by Matson. Contractor is responsible for maintaining training records and providing proof of training if requested by Matson.
The above limits of insurance shall be in no way construed as Contractor’s maximum liability under this Order. Before commencing work under this Order, Contractor will have caused its insurance companies to deliver to Matson certificates of insurance evidencing all insurance required under paragraph (a). All such insurance will provide Matson with 30 days’ prior written notice of cancellation/non-renewal and 10 days’ advance written notice of cancellation for non-payment of premiums. The insurance required under paragraphs (a)(1) and (2) will be endorsed to name Matson as additional insured with respect to liability arising out of work performed by Contractor. Contractor shall require that any subcontractors meet the insurance requirements set forth in this paragraph. Contractor’s insurance shall be primary insurance and not excess over or contributory with any other valid, existing and applicable insurance carried by Matson. All insurance policies of Contractor shall be endorsed to include a waiver of subrogation in favor of Matson. Contractor waives all rights of recovery against Matson to the extent any losses, claims or damages are i) covered by any policy of insurance available to Contractor and/or ii) not covered by Contractor’s insurance because of deductibles, the inadequacy of policy limits, policy limitations or exclusions, or failure to maintain or preserve coverage as required by this Order or by policy terms.
- General. Contractor shall be solely responsible for compliance with all applicable federal, state, local laws, rules and regulations in the performance of its work, or the work of its subcontractors or vendors, or the furnishing of the merchandise, and shall indemnify Matson for any loss, cost or expense resulting from Contractor’s failure to comply. Contractor warrants that Contractor is not (a) a person whose name appears on the list of Specially Designated Nationals and Blocked Persons published by the Office of Foreign Assets Control, U.S. Department of Treasury (“OFAC Listed Person”) or (b) a department, agency or instrumentality of, or is otherwise controlled by or acting on behalf of, directly or indirectly, any OFAC Listed Person or the government of a country subject to comprehensive U.S. economic sanctions administered by OFAC, currently Iran, Sudan, Cuba, Syria and North Korea.
- Federal Contracting Requirements. This Order is subject to the provisions of (i) Executive Order 11246, (41 CFR 60-1.4); (ii) section 503 of the Rehabilitation Act of 1973, (41 CFR 60-741.5(a); and (iii) section 4212 of the Vietnam Era Veterans Readjustment Act of 1974, (41 CFR 60-300.5(a). Matson and Contractor shall abide by the requirements of 41 CFR 60-741.5(a) and 41 CFR 60-300.5(a). These regulations prohibit discrimination against qualified individuals on the basis of disability, and qualified protected veterans, and require affirmative action by covered prime contractors and subcontractors to employ and advance in employment qualified individuals with disabilities, and qualified protected veterans. Contractor and Matson, each for its own part, shall, to the extent applicable, comply with and give all representations and further assurances required by any law or regulation applicable to federal contracts and subcontracts, including, without limitation, the following Federal Acquisition Regulations:
F.A.R. 52.203-6 (Restrictions on Subcontractor Sales to the Government); 52.203-7 (Anti-Kickback Procedures); 52.203-13 (Contractor Code of Business Ethics and Conduct); 52.203-15 (Whistleblower Protections Under the American Recovery and Reinvestment Act of 2009); 52.209-6 (Protecting the Government’s Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment); 52.204-10 (Reporting Executive Compensation and First-Tier Subcontract Awards); 52.204-21 (Basic Safeguarding of Covered Contractor Information Systems); 52.215-2 (Audit and Records – Negotiation); 52.215-13 (Subcontractor Cost or Pricing Data – Modifications); 52.219-8 (Utilization of Small Business Concerns); 52.219-9 (Small Business Subcontracting Plan); 52.219.9 Alt II (Small Business Subcontracting Plan); 52.222-04 (Contract Work Hours and Safety Standards Act – Overtime Compensation); 52.222-17 (Nondisplacement of Qualified Workers); 52.222-21 (Prohibition of Segregated Facilities); 52.222-26 (Equal Opportunity); 52.222-35 (Equal Opportunity for Special Disabled Veterans, Veterans of the Vietnam Era, and Other Eligible Veterans); 52.222-36 (Affirmative Action for Workers with Disabilities); 52.222-37 (Employment Reports on Special Disabled Veterans, Veterans of the Vietnam Era, and Other Eligible Veterans); 52.222-40 (Notification of Employee Rights Under the National Labor Relations Act); 52.222-41 (Service Contract Act of 1965); 52.222-50 (Combating Trafficking in Persons); 52.222-51 (Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment – Requirements); 52.222-53 (Exemption from Application of the Service Contract Act to Contracts for Certain Services-Requirements); 52.222-54 (Employment Eligibility Verification); 52.222-55 (Minimum Wages Under Executive Order 13658); 52.223-15 (Energy Efficiency in Energy-Consuming Products); 52.223-16 (IEEE 1680 Standard for the Environmental Assessment of Personal Computer Products): 52.223-17 (Affirmative Procurement of EPA-designated Items in Service and Construction Contracts); 52.225-8 (Duty-Free Entry); 52.225-13 (Restrictions on Certain Foreign Purchases); 52.225-26 (Contractors Performing Private Security Functions Outside the United States); 52.226-6 (Promoting Excess Food Donation to Nonprofit Organizations); 52.227-1 (Authorization and Consent); 52.227-2 (Notice and Assistance Regarding Patent and Copyright Infringement); 52.232-40 (Providing Accelerated Payments to Small Business Subcontractors); 52.244-6 (Subcontracts for Commercial Items); 52.245-1 (Government Property); 52.247-64 (Preference for Privately Owned U.S.-Flag Commercial Vessels).
For Orders that are subcontracts to a government contract, in addition to the insurances required under paragraph 11, the additional insurance requirements in an attached addendum shall also apply.